Tag Archives: bad faith

Oral Argument Preview: G4S Technology LLC v. Mass. Technology Park Corp.

The Supreme Judicial Court (SJC) is slated to hear oral argument in G4S Technology LLC v. Mass. Technology Park Corp. on Monday, March 5, 2017 – a case with significant implications for construction litigation. The dispute arises out of a $45 million public works project to build a 1200-mile fiber optic network bringing high speed Internet access … Continue Reading

Federal Court Determines that General Contractor’s Unreasonable Exercise of its Broad Discretion over Scheduling and Sequencing of the Work Can Support Bad Faith Exception to “No Damages for Delay” Provisions in Subcontract; but Subcontractor Must Still Submit Delay Claims Within Strict Time Requirements of Subcontract

In a recent decision, Elec. Contractors, Inc. v. Fid. & Deposit Co. of Maryland, No. 3:13-CV-00514 MPS, 2015 WL 1444481 (D. Conn. Mar. 30, 2015), the United States District Court for the District of Connecticut dismissed on summary judgment a subcontractor’s claims for delay damages against the general contractor on a construction project (“Project”) for … Continue Reading