In NASDI, LLC v. Skanska Koch Inc. Kiewit Infrastructure Co. (JV), 2024 WL 1270188 (2d Cir. Mar. 26, 2024), the U.S. Court of Appeals for the Second Circuit affirmed the District Court’s grant of summary judgment dismissing a subcontractor’s delay claim against a general contractor on a public project in New York state. The
General Contractor
New York Restrictions on Flow Through Provision in Subcontracts
By Bill Wilson on
Most subcontracts include a flow through provision (also called flow down and incorporation clauses) stating that the subcontractor and contractor are bound by the same obligations as set forth in the prime contract between the contractor and owner. Many jurisdictions interpret such provisions narrowly, as illustrated in a recent case out of New York. In…